Terms and Conditions

BACKGROUND

MCPC is global data protection company that seeks to improve the security of its customers and protect data while managing the complexity and sustainability of technology in order to reduce business risk. MCPC wishes to provide Customer with certain technology services, and Customer wishes to receive such services, on the terms and conditions set forth in this Agreement.

NOW, THEREFORE, in consideration of the mutual covenants set forth in this Agreement, the Parties agree as follows:

DEFINITIONS

Affiliate means, with respect to each Party, any entity which directly or indirectly controls, is controlled by, or is under common control with, such Party.

Agreement means this Master Services Agreement between MCPC and Customer and any schedules, exhibits or Work Orders attached to it.

Asset Disposition Services means the collection of services associated with managing all asset disposition requirements including logistics, de-installation and removal, packing, receiving, processing, data erasure and destruction, remarketing, and responsible recycling.

Confidentiality Agreement means the Mutual Non-Disclosure Agreement between Customer and MCPC effective as of the last date of signing by the Parties.

Consulting Services means the provision of services to a Customer related to a transfer of knowledge based on Customer’s business or technological concerns, systems, processes, or environment.

Days means calendar days.

Hardware means hardware or product provided to Customer under any Work Order issued hereunder in connection with the Services.

Incident Response means MCPC services relating to a significant and abnormal cybersecurity issue experienced by a Customer for which MCPC has specifically been retained to provide Consulting or other Professional Services to explore, investigate, and/or ameliorate the issue.

Installed Devices means the servers or endpoints on which Customer receives the Managed Security Services. The initial number of Installed Devices will be stated in the applicable Work Order. The number of Installed Devices may be increased from time to time in accordance with this Agreement.

Managed Security Services means the collection of the services and the technology related to software delivery, management and monitoring as specified in the applicable Work Order and the means of delivery of such services and technology, including, if specified in the applicable Work Order, proxy and satellite service (“MSS”). Any use of MSS shall be subject to applicable use policies set forth in the applicable Work Order.

Platform means the combination of the CPU and other hardware a computer system uses, its exact operating system including the version number, the compiler required, the type of libraries (e.g. libc, glibc), and the type of crypto library available (e.g. libcrypt, PAM). Changes to any of these components that break binary compatibility or prohibit functioning (including recompiling) of Software unless modified by MCPC constitute a different Platform and may disqualify Customer from receiving Services with respect to such modified Platform.

Secure Technology Logistics means the services relating to technology planning, procurement, design and/or assessment specified in the applicable Work Order.

Services means the procurement of Hardware or the Secure Technology Logistics, Asset Disposition Services, IT Asset Management Services, Managed Security Services, Consulting Services, Incident Response, Talent Solutions, and any other professional work to be provided by MCPC as specifically set forth in the Work Orders to this Agreement. MCPC may, at its discretion, decline to provide Services for any Software or Hardware that has been modified or changed by Customer in any way, except as directed by MCPC pursuant to this Agreement.

Software means (i) means software owned or licensed by MCPC, which may be provided to Customer under any Work Order issued pursuant to this Agreement in connection with the Services, whether standalone, or as incorporated in Hardware, including any APIs, guides, or documentation provided therewith.; (ii) any MCPC software programs delivered by means of Managed Security Services; and (iii) any other MCPC or third party software product specified in the applicable Work Order, which shall be subject to the applicable end user license agreement set forth in the applicable Work Order.

Supported Hardware or Platform means hardware or a Platform that functions with the Software and components contemplated for use with the Software. Customer agrees that MCPC will have no obligation to provide Services for any system that is not Supported Hardware or Platform unless otherwise stated in an applicable Work Order in connection with custom Services performed by MCPC for the Customer.

Talent Solutions means staff augmentation and recruiting services of personnel for Customer.

Work Order has the meaning set forth in Section 1 below.

SCOPE OF AGREEMENT; WORK ORDERS.
1. This Agreement establishes a framework by which MCPC will provide Services to Customer. The specific Services that MCPC will provide to Customer will be set forth in one or more mutually agreed upon orders for work (each a “Work Order”). Each Work Order will include, to the extent applicable, the following items: (a) description of the Services to be performed and/or provided under the Work Order (b) Customer Contact for the Services to be provided under the Work Order, (c) any deliverables, milestones and target completion dates, (d) any method or schedule for compensation, and (e) Customer’s tasks and the Customer resources required for MCPC to perform the Services. Upon execution by each of the Parties, each Work Order will be a part of, and incorporated into, this Agreement.
  1. A Work Order for Hardware from MCPC may be documented in a separate purchase order for administrative purposes only, are subject to MCPC’s approval, and will be carried out pursuant to the terms of this Agreement
2. Additional or Conflicting Terms. MCPC’s acceptance of any purchase order or similar document submitted by Customer is expressly made in reliance on Customer’s assent to all the terms and conditions of this Agreement. No additional or contradictory terms and conditions included on any Customer purchase order will operate as an amendment to this Agreement, and will have no force and effect, even if such terms and conditions expressly state that they are intended to supersede the terms of this Agreement, MCPC is required to countersign the purchase order, and/or MCPC fails to object to such terms and conditions. Without limiting the generality of the foregoing, in the event of conflicting, contradictory, or additional terms or conditions between this Agreement and any Work Order (including on the face of Customer’s purchase order), this Agreement will control (with exhibits taking precedence over these General Terms and Conditions), unless the Work Order specifically identifies the conflicting or contradicting term or condition as being conflicting or contradicting and specifically notes that the Work Order will control. MCPC’s failure to object specifically to provisions contained in any communication from Customer will not be deemed a waiver of the provisions contained in this Agreement.
  1. A Work Order for the procurement of Hardware will also be bound by the terms and conditions as set forth at www.mcpc.com/terms/stl. In the event of a conflict between this Agreement and the terms and conditions at www.mcpc.com/terms/stl, the terms at www.mcpc.com/terms/stl will take precedence.
OBLIGATIONS OF THE PARTIES
1. MCPC Obligations
  1. MCPC will use commercially reasonable efforts to perform the Services in accordance with the applicable Work Order during the term of this Agreement with respect to Supported Hardware or Platforms.
  2. Customer is entitled to appoint the number of individual contacts (“Customer Contacts”) specified and identified in the applicable Work Order. MCPC will provide Services to Customer solely by communicating with the Customer Contacts.
  3. The Services will be provided in a professional and workman-like manner by qualified personnel.
  4. If applicable, MCPC will provide any Hardware and Software to Customer in conjunction with the Services, subject to the third party provider’s applicable EULA and applicable terms and conditions.
2. Customer Obligations
  1. Customer will appoint the Customer Contacts and provide technical and other assistance required for MCPC to perform the Services on an as needed basis.
  2. Customer shall make commercially reasonable efforts to maintain consistent Customer Contacts for the term of this Agreement or any applicable Work Order. Customer may change a Customer Contact if the individual previously designated has terminated employment with Customer or is no longer involved with day-to-day administration of the Customer’s Supported Hardware or Platform. Customer must notify MCPC of any change in Customer Contacts in writing. Customer shall allow one calendar week for MCPC to process any changes in Customer Contacts.
  3. Customer may not use a Customer Contact to act as a mere forwarding service for other personnel. The Customer Contacts may not use Services to benefit any person or entity other than the Customer.
  4. Customer will perform the tasks and provide the resources specified in the Work Order and this Agreement including, without limitation, workspace and network and telephone connections and access if required to perform the Services.
  5. If Customer provides MCPC with use of, or access to, materials that are subject to proprietary rights of, or controlled by, Customer, Customer hereby grants MCPC, or agrees to obtain for MCPC, all necessary licenses and rights with respect to such materials to perform the Services and Customer warrants that such use or access will not infringe on the rights of any third party.
  6. Customer agrees to provide MCPC all information and all access to Customer’s computer systems and information as reasonably requested by MCPC to enable MCPC to provide the Services. Such information may include, but is not limited to, the type of hardware Customer is using, a description of the problem for which Customer seeks Services, and additional software Customer is using that falls outside the scope of coverage. Customer understands and agrees that the completeness and accuracy of the information Customer provides to MCPC may affect MCPC’s ability to provide Services and/or have an effect on the cost to Customer of the Services.
3. Changes to Work and Delays.
  1. Changes. From time to time, Customer or MCPC may request a change in a Work Order. In such case, Customer and MCPC agree that they will negotiate in good faith regarding any proposed changes to the Work Order. Proposed changes will be affected through a written change order, signed by both parties, and those will constitute amendments to the applicable Work Order. Any work performed under a written change order will be considered Services for purposes of this Agreement. If MCPC agrees to provide additional resources, then such resources will be provided and priced separately.
  2. Delays. In the event that Customer changes any of the specifications of the work to be done, delays the delivery to MCPC of any Customer deliverable specified in the Work Order, delays the start date of the Services, fails to provide MCPC information necessary for MCPC to perform the Services or in any way causes delays to the work schedule, MCPC is entitled to modify the schedule or reschedule the Services, with no penalty to MCPC.
  3. Cancellation. Customer may not cancel a Work Order, in whole or in part, without MCPC’s prior written approval (which may be granted or withheld in MCPC’s sole discretion). Notwithstanding MCPC’s right to grant or withhold such approval, for any Work Order so cancelled, Customer will be responsible for, and will pay to MCPC, on demand: (i) any expenses incurred by MCPC in modifying, adapting or creating any specially ordered Services on Customer’s behalf, including work in progress; and (ii) out-of-pocket costs incurred by MCPC arising from such cancellation (including the amount charged to MCPC from its manufacturers, vendors, distributors, or subcontractors caused by Customer’s request for cancellation).
  4. Returns. Customer may only return purchased Hardware in accordance with MCPC’s Return Policy (www.mcpc.com/Merchandise-Returns-Policy). Customer should contact MCPC to initiation a return or for additional information.
INTELLECTUAL PROPERTY RIGHTS.
1. Customer Pre-Existing Property. Customer will retain all right, title and interest in and to all pre-existing information, ideas, data, software, tools and other materials developed by or for Customer prior to commencement of the Services (“Customer Pre-Existing IP”). Customer grants to MCPC a non-exclusive, worldwide, royalty-free license to use the Customer Pre-Existing IP solely for MCPC to perform the Services.
2. MCPC Pre-Existing Property. MCPC will retain all right, title and interest in and to all pre-existing information, data, software, tools and other materials developed by or for MCPC prior to commencement of the Services (“MCPC Pre-Existing IP”).
3. Deliverables. Customer will own all right, title and interest in and to the deliverables set forth in the Work Order (“Deliverables”). To the extent that the Deliverables contain MCPC Pre-Existing IP and subject to the terms and conditions of this Agreement, MCPC grants to Customer a perpetual, non-exclusive, worldwide, non-transferable, non-sublicensable, royalty-free license to use such MCPC Pre-Existing IP solely in connection with the Deliverables.
4. Third Party Materials. Any pre-existing information, data, software, tools and other materials developed by any third-party licensor of MCPC (“Third Party Materials”) that is included in the Deliverables will remain the property of such third party licensor and MCPC grants to Customer a perpetual, non-exclusive, worldwide, non-transferable, non-sublicensable, royalty-free license to use such Third Party Materials solely in connection with the Deliverables.
5. Deliverables and Software. MCPC agrees that (a) the data and information (including without limitation, computer software, computer database, computer software documentation, specifications, design drawings, reports, blueprints and the like) generated by MCPC in the performance of the Services and derived from the Deliverables and (b) any data and information that are specified to be delivered or that are in fact delivered to Customer pursuant to this Agreement, which data and information are derived from Customer’s proprietary data and information shall be and remain the sole property of Customer; provided, however that the Software and any data or information (including without limitation, computer software, computer database, computer software documentation, specifications, design drawings, reports, blueprints) that is the property of MCPC shall remain the property of MCPC. Any ideas, data, software, tools, and other materials developed by MCPC during the course of the engagement which are not specified in the Work Order, do not arise from Customer’s proprietary data and information, or are not otherwise derived directly from the Deliverables shall remain the property of MCPC.
6. MCPC Marks. No right or license, express or implied, is granted by this Agreement for the use of any of MCPC’s trademarks, including, without limitation, the distribution of the Software utilizing any MCPC trademarks.
FEES, INVOICES, TAXES, REPORTING AND AUDIT.
1. Fees and Expenses. All fees are stated in the currency designated in the Work Order, and must be paid by Customer to MCPC in that designated currency without deduction or set-off. Customer will reimburse MCPC for its reasonable, out-of-pocket expenses in performing the Services including without limitation travel, lodging, shipping, courier, document reproduction, postage, and non-routine supplies, in accordance with MCPC’s travel and expense policies.
2. Invoice. MCPC will invoice Customer for the agreed upon fees in accordance with the applicable Work Order. Any and all payments made by Customer pursuant to this Agreement are non-refundable. Customer will make payment within thirty (30) days of the date specified on the invoice. MCPC reserves the right to terminate this Agreement if actual payment has not been received within the aforementioned thirty (30) day period. However, MCPC will notify Customer before such termination and will give Customer 14 days from receipt of said notice before actually terminating this Agreement to either: (a) provide MCPC with a written explanation of its inability to pay; or (b) to remit payment to MCPC.
3. Taxes. All fees for Services are exclusive of any taxes due to be paid under the applicable laws including national, federal, state, local, VAT, sales, excise, use, or similar taxes. Except for taxes relating to MCPC’s income, Customer agrees to pay all other taxes that, as per applicable under the applicable laws, are incumbent on the buyer or beneficiary of the Services provided by MCPC to Customer hereunder.
4. Audit. During the term of this Agreement and for one (1) year thereafter, MCPC has right to audit Customer’s facilities and records from time to time in order to verify Customer’s compliance with the terms and conditions of this Agreement. Any such audit will only take place during Customer’s normal business hours and upon no less than ten (10) days prior written notice from MCPC. MCPC will conduct no more than one such audit in any twelve-month period except for the express purpose of assuring compliance by Customer where non-compliance has been established in a prior audit. MCPC will give Customer written notice of any non-compliance, and Customer will have fifteen (15) days from the date of such notice in which to make payment to MCPC for such deficiency.
5. Prepay. All amounts due and paid in advance are applicable solely to that contract as described in the applicable Order Document; such amounts may not be used or applied towards any other obligations Customer may have towards MCPC, whether as an offset, recoupment, indemnification or any other defense to payment except for claims arising out of that Order Document because of defects in the specific goods or services described in such Order Document.
TERM AND TERMINATION.
1. Term. The term of this Agreement will begin on the Effective Date and will terminate when MCPC has performed all Services under any Work Order and the parties have not entered into any new Work Order for a period of 180 days, unless terminated earlier in accordance with Section 4.2 or 5.2. If no Effective Date is given, the term shall begin upon the second signature of the two parties to the Agreement.
2. Termination. This Agreement may not be terminated by either MCPC or Customer except as follows: (a) as provided under Sections 4.2 or 5.1, (b) by either Party upon fifteen (15) days prior written notice for any material default or breach of the terms and conditions of the Agreement by the other Party, unless the defaulting Party has cured such failure or default within such 15-day period, provided however, that no such cure period will be permitted for a breach of Section 7.1 hereof.
3. Effect of Termination. If this Agreement is terminated for any reason, the obligations of the Parties under Sections 3, 4 and 6 through 11 of this Agreement will survive such termination.
DISCLAIMER OF DAMAGES AND LIMITATION OF LIABILITY.
1. TO THE MAXIMUM EXTENT PERMITTED BY APPLICABLE LAW, IN NO EVENT WILL MCPC BE LIABLE TO CUSTOMER OR ANY THIRD PARTY FOR ANY INCIDENTAL, CONSEQUENTIAL, SPECIAL OR PUNITIVE DAMAGES, WHETHER IN TORT OR IN CONTRACT, INCLUDING LOST PROFITS, LOST SAVINGS OR OTHER INCIDENTAL OR CONSEQUENTIAL DAMAGES ARISING OUT OF (A) THE SERVICES, (B) ANY INTERRUPTION OF USE OF THE SERVICES, OR (C) FOR LOSS, INACCURACY OR CORRUPTION OF DATA, EVEN IF MCPC HAS BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.
2. MCPC’S LIABILITY HEREUNDER WILL BE LIMITED TO DIRECT DAMAGES NOT TO EXCEED THE AMOUNT THAT CUSTOMER PAID TO MCPC FOR THE SERVICES AND/OR THE SOFTWARE OR HARDWARE FROM WHICH THE LIABILITY AROSE AT THE TIME OF THE EVENT GIVING RISE TO THE LIABILITY.
DATA Security and Privacy
1. In providing the Services, MCPC will (i) store, process and access Customer Data only to the extent reasonably necessary to provide or improve the Services, and (ii) implement and maintain commercially reasonable technical, physical and organizational measures to protect the security, confidentiality and integrity of Customer Data hosted by MCPC or our authorized third party service providers, from unauthorized access, use, alteration or disclosure.
CONFIDENTIALITY AND PUBLICITY.
1. Confidentiality. The Parties agree that confidential information exchanged under this Agreement will be treated in accordance with the Confidentiality Agreement.
2. Publicity. Each Party agrees not to use the name of other Party or any trademark, trade name or service mark or symbol owned by the other Party or otherwise refer to the other Party in writing to any third party without the prior written consent of the other Party; provided however, MCPC may reference its relationship to Customer during discussions with financial analysts, presentations to investors, meetings with the press and Customer briefings.
WARRANTY. EXCEPT AS OTHERWISE PROVIDED IN THIS AGREEMENT, MCPC DOES NOT PROVIDE ANY WARRANTY WITH RESPECT TO HARDWARE, SOFTWARE, OR Services. Except as provided in this Agreement, THE SERVICES ARE PROVIDED “AS IS” AND WITHOUT WARRANTIES OR CONDITIONS OF ANY KIND, INCLUDING THE IMPLIED WARRANTIES OF MERCHANTABILITY, NON-INFRINGEMENT, AND FITNESS FOR A PARTICULAR PURPOSE. THIS IS THE SOLE AND EXCLUSIVE WARRANTY GIVEN BY MCPC (EXPRESS OR IMPLIED) WITH RESPECT TO THE SUBJECT MATTER OF THIS AGREEMENT. MCPC DOES NOT GUARANTEE OR WARRANT THAT THE USE OF THE SERVICES WILL NOT BE INTERRUPTED OR ERROR FREE.
GOVERNING LAW/CONSENT TO JURISDICTION. THE VALIDITY, INTERPRETATION AND ENFORCEMENT OF THIS AGREEMENT WILL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE LAWS OF THE STATE OF OHIO. CUSTOMER HEREBY CONSENTS TO JURISDICTION OF THE COURTS OF BOTH THE STATE OR FEDERAL COURTS OF CUYAHOGA COUNTRY, OHIO.
GENERAL PROVISIONS.
1. Notices. Any notice to be given pursuant to this Agreement, including any notice of change of address for notice, will be deemed given (a) three (3) business days after being deposited with the U.S. Postal Service, postage prepaid, first class, certified, return receipt requested; (b) upon receipt when delivered in person; (c) two (2) business days after being deposited with a reputable international overnight delivery service; or (d) one (1) business day after being transmitted by facsimile with confirmation of delivery to the address or facsimile telephone number for such party set forth below. If to MCPC: MCPC, Inc. Attention: General Counsel 21500 Aerospace Parkway Cleveland, OH 44142 Email: [email protected]
2. Assignment. This Agreement is assignable by Customer only with MCPC’s prior written consent, which will not be unreasonably withheld. If Customer is assigning this Agreement to an Affiliate, or as a result of a merger or a sale of all or substantially all of Customer’s assets or stock, then prior approval for the assignment is not required as long as the cost and/or number of persons supported does not increase as a result of such assignment and the rights, risks and obligations of MCPC are not adversely affected. MCPC may subcontract Services under this Agreement without the prior approval of Customer; provided, however, that such subcontrator must agree to keep any proprietary information received from MCPC or Customer confidential.
3. Independent Contractor. MCPC is an independent contractor and nothing in this Agreement or related to MCPC’s performance of any Work Order will be construed to create an employee relationship between Customer and MCPC or any MCPC consultant. MCPC will be solely responsible for payment of applicable taxes, deductions or other payments and benefits for its personnel.
4. Export Responsibilities. MCPC may supply Customer with technical data that may be subject to export control restrictions. MCPc will not be responsible for compliance by Customer with applicable export obligations or requirements for such technical data and hardware. Customer agrees to comply with all applicable export control restrictions.
5. Headings. The title and paragraph headings contained in this Agreement are inserted for identification and convenience and will not be deemed part of this Agreement for purposes of interpretation.
6. Severability. If any provision of this Agreement is held invalid or unenforceable for any reason, the Parties agree that such invalidity will not affect the validity of the remaining provisions of the Agreement and further agree to substitute for the invalid provision a valid provision that most closely approximates the intent and economic effect of the invalid provision.
7. Waiver. The failure of either Party to exercise any rights hereunder will not constitute or be deemed a waiver of forfeiture of such rights.
8. Dispute Resolution. Customer satisfaction is an important objective to MCPC in performing its obligations under this Agreement. If Customer is not satisfied with the Services provided by MCPC, Customer agrees to give MCPC a written description of the problem(s) and to make a good faith effort to amicably resolve the problem with MCPC before commencing any proceeding. MCPC also agrees to make a good faith effort to amicably resolve any problem with Customer before commencing any proceeding.
9. Prevailing Party. In the event of a dispute between the Parties regarding payment under this Agreement, the prevailing Party’s reasonable attorney’s fees will be paid by the other Party.
10. Force Majeure. Neither Party will be liable for nonperformance or delays caused by acts of God, wars, riots, strikes, fires, floods, earthquakes, government restrictions or other causes beyond its control. In the event of the occurrence of any of the foregoing, the date of performance will be deferred for a period of time equal to the time lost by reason of the delay. The affected Party will notify the other in writing of such events or circumstances promptly upon their occurrence.
11. Complete Agreement. This Agreement and Work Orders that are executed by each of the Parties under this Agreement will constitute the exclusive terms and conditions with respect to the purchases of Software or Services under this Agreement by Customer from MCPC, notwithstanding any different or additional terms that may be contained in the form of purchase order or other document used by Customer in such transactions. This Agreement and the Work Orders that are executed by each of the Parties under this Agreement contains the final, complete and exclusive statement of the agreement between the parties with respect to the transactions contemplated herein and all prior written agreements and all prior and contemporaneous oral agreements with respect to the subject matter herein are merged herein. This Agreement and any Work Order that is executed by each of the Parties under this Agreement may not be amended, supplemented or modified (or any right or power granted hereunder waived) except by written instrument signed by authorized officers of the parties hereto (or in the case of a waiver, signed by the party to be bound), which instrument makes specific reference to this Agreement or the applicable Work Order. In the event of any conflict between this Agreement and any Work Order, this Agreement will take precedence unless otherwise specified in the Work Order.
12. Non-Solicitation. Customer agrees not to solicit or hire any personnel of MCPC with whom Customer has had contact in connection with this Agreement until at least one year after the termination of this Agreement.
13. Counterparts and Facsimile Signature. This Agreement may be executed in counterparts, each of which will be deemed an original and all of which will constitute the same agreement. The Parties may exchange signature pages by facsimile and such signatures will be effective to bind the Parties.

These Operating Terms and Conditions for Secure Technology Logistics (STL) Services and the Procurement of Hardware apply to any Services offered by MCPC that relate to its STL practice or the purchase and procurement of Hardware under any services offered by MCPc. These terms are incorporated into any Order Document under which STL Services are performed or Hardware is purchased. In the event of a conflict between these terms and the Order Document, the terms of the applicable Order Document shall prevail.

Definitions
1. “Configuration-related Services” means a portfolio of services that include hardware and software settings, operation system settings, software image load and provisioning, application installation, asset reporting, asset identification and tagging, and hardware component integration.
2. “Deployment Services” means work performed at a Customer’s location or remote to activate a device and therefore making it ready for production.
3. “First Article Build Approval” means the document that outlines the image to be used and deployed on Customer Hardware as approved by MCPC and Customer.
4. “Hardware” means hardware, if any, provided to Customer under any Order Document issued hereunder in connection with the Services.
5. “Transition Services” means the method to plan, validate, and activate the ordered Services in a coordinated manner.
QUOTATIONS AND PRICING.
1. Any Hardware or pricing referred to in a MCPC quotation is subject to availability and does not constitute an offer by MCPC. MCPC reserves the right to change prices for Hardware at any time, effective immediately upon notice to Customer, for all orders of Hardware submitted following the effective date of such notice. Quotations are valid only for the time period listed on the quote; any quote or pricing which has passed the validity date will not be honored or accepted by MCPC.
2. All amounts due and paid in advance are applicable solely to that contract as described in the applicable Order Document; such amounts may not be used or applied towards any other obligations Customer may have towards MCPC, whether as an offset, recoupment, indemnification or any other defense to payment except for claims arising out of that Order Document because of defects in the specific goods or services described in such Order Document
SHIPPING.
1. For Hardware shipped directly from the manufacturer to the Customer: Products are shipped F.O.B. point of origin. Title to Hardware (excluding any Software embedded on or provided with the Hardware) and risk of loss will pass upon manufacturer’s delivery of Hardware to carrier.
2. For Hardware shipped by MCPC from its facilities to the Customer: Title to Hardware (excluding any Software embedded on or provided with the Hardware) and risk of loss will pass upon MCPC’s delivery of Hardware to carrier, or as otherwise specified in an applicable Order Document. If Hardware is delivered by MCPC, title will transfer upon acceptance of Hardware at Customer dock.
3. Customer will pay all shipping, handling, freight, delivery, customs, duties, taxes, special packing, and insurance charges for shipments of Hardware. Choice of carrier and shipping method will be at the election of MCPC. All shipments will be made to the address specified in the applicable Order Document. MCPC reserves the right to make delivery in installments, with all such installments to be separately invoiced and paid for individually, without regard to subsequent deliveries. Delay in delivery of any installment will not relieve Customer of its obligation to accept remaining deliveries. Returns of Hardware will not be permitted unless expressly authorized in writing by MCPC.
4. Pre-established shipping schedules and programs may be agreed to in an Order Document, should this schedule and/or program be adjusted by the customer, MCPC will invoice the customer for any additional costs that are incurred.
DELIVERY. Customer agrees to assume the risk of casualty or damage to the Hardware from the date of delivery acceptance at Customer’s premises. No casualty or damage, after such delivery, will relieve Customer from the obligation to make payments or to comply with any other obligations under this Agreement. Customer’s acceptance of delivery of any Hardware hereunder will be deemed Customer’s acknowledgement that (a) all of the Hardware listed in the applicable Order Document has been received, and (b) such Hardware shows no obvious signs of physical damage.
ACCEPTANCE.
1. Upon receipt of Hardware, Customer agrees to inspect and/or test the Hardware. The Hardware will be deemed accepted by Customer unless Customer provides MCPC, within 10 days of the delivery date, a written notice specifying all defects or discrepancies in the quality or quantity of Hardware.
2. If Customer refuses or fails to take delivery of Hardware provided in accordance with this Agreement, any risk of loss of or damage to the Hardware will nonetheless pass to Customer, without prejudice to any other rights or remedies MCPC may have, including: (i) MCPC will be entitled to immediate payment in full for the Hardware (and related Services) ordered, and either to effect delivery by whatever means MCPC considers appropriate, or to store Hardware at Customer’s sole risk and expense; (ii) Customer will be liable and pay on demand all costs of Hardware storage and additional costs incurred as a result of Customer’s refusal or failure to take delivery; and (iii) if Customer refuses to take delivery for thirty (30) days, MCPC may dispose of the Hardware ordered by Customer, at MCPC’s discretion.
SECURITY INTEREST.
1. Customer hereby grants to MCPC a security interest and lien in the Hardware wherever located, and all replacements of the Hardware, or cash proceeds, to secure the obligations of the Customer to pay for such Hardware; provided, however, that MCPC agrees to release such security interest upon the reasonable request of the Customer in the event that Customer provides MCPC collateral in substitution therefor which is acceptable to MCPC in MCPC’s sole discretion. Such interest shall be released upon payment in full for the Hardware. Customer will execute and return for filing all documents reasonably requested by MCPC for the perfection of such security interests, such as a form UCC-1, and MCPC may file a copy of this Agreement in connection therewith. Customer will not grant any lien to any third party on any Hardware or proceeds without the prior written consent of MCPC.
INSURANCE.
1. Until the purchase price and all related amounts for each unit of the Hardware is paid in full, Customer agrees, at its own cost and expense, to (a) keep such Hardware fully insured against loss; and (b) provide MCPC, at MCPC’s option, certificates or other evidence of such insurance reasonably acceptable to MCPC.
SECURE TECHNOLOGY LOGISTICS OPERATING ASSUMPTIONS
1. Payment of hardware purchased with installation & deployment services, unless agreed to in writing will not be contingent upon performance or delivery of services purchased with such hardware.
2. Transition Services will be invoiced upon MCPC’s acceptance of the Customer’s purchase order or upon acceptance of an applicable Order Document.
3. Configuration-related services will be invoiced when the related device is shipped.
4. Deployment services will be invoiced on a weekly basis for deployments completed that week.
5. For subscribed services on a calendar term that are billed monthly, see Subscription Services Terms in Section 13.
6. Standard business hours are 8:00am to 5:00pm local time, Monday – Friday excluding MCPC holidays. Services performed outside of standard business hours will incur additional charges as applicable.
ADVANCED HARDWARE REPLACEMENT
1. Customer is responsible for any required data backup unless otherwise specifically provided for in applicable Order Document.
2. All Customer devices on which services are performed as part of Advanced Hardware Replacement must be encrypted. MCPC HEREBY DISCLAIMS ALL LIABILITY RESULTING OR ARISING FROM ANY CUSTOMER DEVICE ON WHICH SERVICES ARE PERFORMED UNDER ADVANCED HARDWARE REPLACEMENT THAT IS NOT ENCRYPTED TO A REASONABLE INDUSTRY STANDARD.
Third Party Products
1. If MCPC receives a shipment to any of its facilities for goods associated with a Customer or Customer’s project which have not be ordered through or by MCPC, and MCPC has not been alerted to the arrival of these goods or has not otherwise agreed to receive them, in its sole discretion, MCPC disclaims any and all liability resulting from the receiving, processing, storage, packaging, or any other actions associated with such goods. MCPC will invoice Customer for any cost related to the receiving, handling, and shipping of these goods. MCPC is also not responsible for any delays in services caused by the receipt of any such goods.
FIRST ARTICLE BUILD.
1. Any time a Customer requires a new computer image, makes a change to their previously approved image, or a change in the process for imaging the Hardware for an ongoing Service, MCPC may require a First Article Build Approval document to be signed. MCPC will provide this document to Customer and Customer must complete the document and the process described therein, and return with a signature or other approved sign-off before the Services may commence.
SUBSCRIPTION SERVICES TERMS: Unless otherwise specified in an applicable Order Document, Services offered on a calendar-based, subscription service model (“Subscription Services”) are subject to the following terms and conditions:
1. Term:
  1. Subscription Services will be outlined in an Order Document which will incorporate these Operational Terms and Conditions, and, together with the Master Services Agreements, form the Subscription Agreement (“Agreement”).
  2. All Agreements will include the date on which the Order Document was fully executed (“Effective Date”) and the date on which the Services will begin for the Customer (“Service Initiation Date.”) Onboarding fees shall be invoiced at the Effective Date.
  3. The Services will begin on the Service Initiation Date and end at the conclusion of the term identified in the applicable Order Document (“Service Term”). The minimum term shall be one year.
  4. At the end of the Service Term, the Agreement will automatically renew for successive one-year term unless the Customer notifies MCPC in writing sixty (60) days prior to the termination date.
2. Pricing:
  1. Pricing for each service to be performed will be listed in the applicable Order Document. Pricing will be valid above the minimum and up to the maximum quantities listed in the Order Document, if applicable
  2. Pricing is subject to change upon renewal of the Agreement. Updated pricing for renewal terms will be periodically communicated to Customers in writing. Pricing updates announced within the termination notice period will not take effect until the subsequent renewal term.
    1. Regardless of the above Section 13.2.2, if Customer receives the pricing update before the termination notice period, Customer shall have a minimum of ten days from the receipt of a pricing update to accept or reject a renewal of the Services Agreement.